The URL can be used to link to this page

AIA Weitz Company1-11;AIA Document A101TM - 2007 Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum AGREEMENT made as of the Tenth day of November in the year Two Thousand Fifteen (In tivords, indicate day, month and year:) ADDITIONS AND DELETIONS: The author of this document has BETWEEN the Owner: added information needed for its (Name, legal status, address and other information) completion. The author may also have revised the text of the original Blair Public Library Foundation AIA standard form. An Additions and P.O. Box 743 Deletions Report that notes added Blair, Nebraska 68008 information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical line in the left margin of this and the Contractor: document indicates where the author (Name, legal status, address and other information) has added necessary Information and where the author has added to or The Weitz Company deleted from the original AIA text. 8715 South 121st Street This document has important legal LaVista, Nebraska 68128 consequences. Consultation with an attorney Is encouraged with respect to its completion or modification. for the following Project: AIA Document A201 TM -2007, (Name, location and detailed description) General Conditions of the Contract for Construction, is adopted in this document by reference. Do not use Blair Public Library and Technology Center Building Package with other general conditions unless this document is modified. The Architect: (Name, legal status, address and other information) The Clark Enersen Partners 1010 Lincoln Mall, Suite 200 Lincoln, Nebraska 68508 The Owner and Contractor agree as follows. Init. AIA Document A101T"' - 2007. Copyright ©1915,1918,1925,1937,1951, 1968, 1961,1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This Ale Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproductiomor distribution of this AIA° Document, or any portion of it, may resuit.in severe civil and criminal penalties, and will be prosecuted to the t maxWum extent possible under the law. This documentwas produced byAIA software at 13:62:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) TABLE OF ARTICLES 1 THE CONTRACT DOCUMENTS 2 THE WORK OF THIS CONTRACT 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 4 CONTRACT SUM 5 PAYMENTS 6 DISPUTE RESOLUTION 7 TERMINATION OR SUSPENSION 8 MISCELLANEOUS PROVISIONS 9 ENUMERATION OF CONTRACT DOCUMENTS 10 INSURANCE AND BONDS ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, Addenda issued prior to execution of this Agreement, other documents listed in this Agreement and Modifications issued after execution of this Agreement, all of which form the Contract, and are as fully a part of the Contract as if attached to this Agreement or repeated herein. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. An enumeration of the Contract Documents, other than a Modification, appears in Article 9. ARTICLE 2 THE WORK OF THIS CONTRACT The Contractor shall fully execute the Work described in the Contract Documents, except as specifically indicated in the Contract Documents to be the responsibility of others. ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement shall be contained in the Notice to Proceed. (Paragraphs deleted) § 3.2 The Contract Time shall be measured fi•om the date of commencement. § 3.3 The Contractor shall achieve Substantial Completion of the entire Work not later than ( ) days from the date of commencement, or as follows: (Insert number of calendar days. Alternatively, a calendar date may be used when coordinated with the date of commencement. If appropriate, insert requirements far earlier Substantial Completion of certain portions of the Worlc.) The Contractor shall achieve Substantial Completion of the entire Work not later than July 1, 2017. If the work is not substantially complete on or before this date, or within this period of time, or extension thereof granted by the Owner, damage will be sustained by the Owner and that it is and will be impracticable and extremely difficult to fix the actual damage which the Owner will sustain in the event of and by reason of such delays. The Contractor shall pay to the Owner liquidated damages in the sum of $0.00 for each calendar day of delay. Any sums that may be due the Owner as liquidated damages may be deducted from any monies due or to become due the Contractor under the Contract or may be collected from the Contractor's surety. (Table deleted) Init. AIA Document A101 TM — 2007. Copyright©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA° Document is protected by U.S. Copyright Law and International Treaties. Unauthorized 2 reproductioh or distribution of this AIA° Document, or any portion of it, may result in, severe civil and criminal p6nalties, and will be prosecuted to the t maximum extent possible under the law, This document was produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491 1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) , subject to adjustments of this Contract Time as provided in the Contract Documents. (Insert provisions, if any, for liquidated damages relating to failure to achieve Substantial Completion on time or for bonus payments for early completion of the Work.) ARTICLE 4 CONTRACT SUM § 4.1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor's performance of the Contract. The Contract Sum shall be Four Million Two Hundred Twenty-two Thousand Five Hundred Dollars and Zero Cents ($ 4,222,500.00 ), subject to additions and deductions as provided in the Contract Documents. § 4.2 The Contract Sum is based upon the following alternates, if any, which are described in the Contract Documents and are hereby accepted by the Owner: (State the numbers or other identification of accepted alternates. If the bidding or proposal documents permit the Owner to accept other alternates subsequent to the execution of this Agreement, attach a schedule of such other alternates showing the amountfor each and the date when that amount expires) Base bid: $4,075,000.00 A-3: +$17,500.00 L-1: +$20,000.00 E-1: +$110,000.00 Total: $4,222,500.00 § 4.3 Unit prices, if any: (Identify and state the unitprice; state quantity limitations, if any, to which the unit price will be applicable) Item Price Per Unit ($0.00) Unit Price No. 1 $39.00/SY Unit Price No. 2 $4.50/SF Unit Price No. 3 $260.00/SF § 4.4 Allowances included in the Contract Sum, if any: (Idents allowance and state exclusions, if any, from the allowance price) ('fable deleted) ARTICLE 5 PAYMENTS § 5.1 PROGRESS PAYMENTS § 5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents. § 5.1 .2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month, or as follows: § 5.1.3 Provided that an Application for Payment is received by the Architect not later than the Thirtieth day of a month, the Owner shall make payment of the certified amount to the Contractor not later than the Thirtieth day of the following month. If an Application for Payment is received by the Architect after the application date fixed above, payment shall be made by the Owner not later than Forty-five ( 45 ) days after the Architect receives the Application for Payment. (Federal, state or local laws may require payment within a certain period of time) § 5.1.4 Each Application for Payment shall be based on the most recent schedule of values submitted by the Contractor in accordance with the Contract Documents. The schedule of values shall allocate the entire Contract Sum among the various portions of the Work. The schedule of values shall be prepared in such form and supported by such data to Init. AIA Document A101 TM — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This Ale Document is protected by U.S. Copyright Law and International Treaties. Unauthorized 3 reproduction or distribution of this AIA ' Document, or any portion of It, may result in severe :civil and criminal penalties, and will be prosecuted to the t maximum extent possible.under.the law, This documentwas produced byAlAsofiware at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) substantiate its accuracy as the Architect may require. This schedule, unless objected to by the Architect, shall be used as a basis for reviewing the Contractor's Applications for Payment. § 5.1.5 Applications for Payment shall show the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. § 5.1.6 Subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: .1 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the Contract Sum allocated to that portion of the Work in the schedule of values, less retainage of Ten percent (10.00 %).; .2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction, less retainage of Ten percent (10.00 %); .3 Subtract the aggregate of previous payments made by the Owner; and .4 Subtract amounts, if any, for which the Architect has withheld or nullified a Certificate for Payment as provided in Section 9.5 of AIA Document A201-2007, § 5.1.7 The progress payment amount determined in accordance with Section 5.1.6 shall be further modified under the following circumstances: .1 Add, upon Substantial Completion of the Work, a sum sufficient to increase the total payments to the full amount of the Contract Sum, less such amounts as the Architect shall determine for incomplete Work, retainage applicable to such work, and unsettled claims; and (Section 9.8.5 of AIA Document.4201 2007 requires release of applicable retainage upon Substantial Completion of Work tivith consent of surety, if any) .2 Add, if final completion of the Work is thereafter materially delayed through no fault of the Contractor, any additional amounts payable in accordance with Section 9.10.3 of AIA Document A201-2007. § 5.1.8 Reduction or limitation of retainage, if any, shall be as follows: (If it is intended, prior to Substantial Completion of the entire Work, to reduce or limit the retainage resulting from the percentages inserted in Sections 5.1.6.1 and 5.1.6.2 above, and this is not explained elsewhere in the Contract Documents, insert here provisions for such reduction or limitation.) The amount retained shall be 10% of the value of Work until 50% of the Work has been completed. At 50% completion, further partial payments shall be made in full to the Contractor and no additional amounts may be retained unless the Architect certifies that the Work is not proceeding satisfactorily, but amounts previously retained shall not be paid to the Contractor. At 50% completion or any time thereafter when the progress of the Work is not satisfactory, additional amounts may be retained but in no event shall the total retainage be more than 10% of the value of Work completed. § 5.1.9 Except with the Owner's prior approval, the Contractor shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site. § 5.2 FINAL PAYMENT § 5.2.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when .1 the Contractor has fully performed the Contract except for the Contractor's responsibility to correct Work as provided in Section 12.2.2 of AIA Document A201 2007, and to satisfy other requirements, if any, which extend beyond final payment; and .2 a final Certificate for Payment has been issued by the Architect. § 5.2.2 The Owner's final payment to the Contractor shall be made no later than 30 days after the issuance of the Architect's final Certificate for Payment, or as follows: AIA Document A101 "I — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Init. Institute of Architects. All rights reserved. WARNING: This AIA' Document is, protected by U.S. Copyright Law and International Treaties. Unauthorized 4 reproduction or distribution of this AIA° ©ociiment, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the i maximum extent possible under the law. This documentwas produced byAlAsofi'Nare at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) ARTICLE 6 DISPUTE RESOLUTION § 6.1 INITIAL DECISION MAKER The Architect will serve as Initial Decision Maker pursuant to Section 15.2 of AIA Document A201 2007, unless the parties appoint below another individual, not a party to this Agreement, to serve as Initial Decision Maker. (If the parties mutually agree, insert the name, address and other contact information of the Initial Decision Maker, if other than the Architect.) § 6.2 BINDING DISPUTE RESOLUTION For any Claim subject to, but not resolved by, mediation pursuant to Section 15.3 of AIA Document A201 2007, the method of binding dispute resolution shall be as follows: (Check the appropriate box. If the Owner and Contractor do not select a method of binding dispute resolution below' or do not subsequently agree in writing to a binding dispute resolution method other than litigation, Claims will be resolved by litigation in a court of competentjurisdiction) [ ] Arbitration pursuant to Section 15.4 of AIA Document A201-2007 [ X ] Litigation in a court of competent jurisdiction [ ] Other (Spec) ARTICLE 7 TERMINATION OR SUSPENSION § 7.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A201-2007. § 7.2 The Work may be suspended by the Owner as provided in Article 14 of AIA Document A201-2007. ARTICLE 8 MISCELLANEOUS PROVISIONS § 8.1 Where reference is made in this Agreement to a provision of AIA Document A201-2007 or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. § 8.2 Payments due and unpaid under the Contract shall bear interest from the date payment is due at the rate stated below, or in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located. (Insert rate of interest agreed upon, if any) 6.00 % per annum § 8.3 The Owner's representative: (Name, address and other information) Rodney Storm Blair City Administrator 218 South 16th Street Blair, Nebraska 68008 § 8.4 The Contractor's representative: (Name, address and other information) Brian Malhendorf The Weitz Company 8715 South 121 st Street LaVista, Nebraska 68128 AIA Document A101 Th' — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961 1963, 1967 1974, 1977, 1987, 1991, 1997 and 2007 by The American Inst. Institute of Architects. All rights reserved. WARNING: This AIA° Document is protected,by U.S.Copyright Law and International Treaties, Unauthorized 5 reproduction.or distribution of this Ale Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the t maximum extent possible under the law. This documentwas produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and Is not for resale. User N otes: (947285321) § 8.5 Neither the Owner's nor the Contractor's representative shall be changed without ten days written notice to the other party. § 8.6 Other provisions: § 8.6.1 This Agreement shall not become effective until concurred in writing by the Agency. Such concurrence shall be evidences by the signature of a duly authorized representative of the Agency in the space provided at the end of this Attachment to the Agreement. The concurrence so evidenced by the Agency shall in no way commit the Agency to render financial assistance to the Owner and is without liability to the Agency for any payment thereunder, but in the event such assistance is provided, the concurrence shall signify the provisions of this Agreement are consistent with Agency requirements. ARTICLE 9 ENUMERATION OF CONTRACT DOCUMENTS § 9.1 The Contract Documents, except for Modifications issued after execution of this Agreement, are enumerated in the sections below. § 9.1.1 The Agreement is this executed AIA Document A101-2007, Standard Form of Agreement Between Owner and Contractor. § 9.1.2 The General Conditions are AIA Document A201-2007, General Conditions of the Contract for Construction. § 9.1.3 The Supplementary and other Conditions of the Contract: Document Title Date Pages 01 1000 Attachment to the Standard Form of Agreement October 2015 4 01 22 00 Between Owner and Contractor October 2015 3 01 23 00 General Conditions of the Contract for Construction, October 2015 3 01 2500 AIA 201-2007 October 2015 3 01 26 00 Attachment to the General Conditions of the Contract October 2015 3 01 9-900 for Construction (RD Instruction 1942-A, Guide 27, October 2015 5 01 3100 Attachment 4) October 2015 7 01 3300 Special Conditions October 2015 8 Project Manual Advertisement for Bids October 2015 2 Project Manual Instructions to Bidders October 2015 1 Project Manual Supplementary Instructions to Bidders October 2015 1 Project Manual Geotechnical Data December 15, 2014 39 Project Manual Bid Form October 2015 3 Project Manual General Conditions October 2015 1 Project Manual Supplementary Conditions October 2015 15 § 9.1.4 The Specifications: (Either list the Specifications here or /refer to an exhibit attached to this Agreement) Section Title Date Pages Init. AIA Document A101 TM — 2007. Copyright ©1915, 1918, 1925, 1937 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA° bocument is protected by U.$: Copyright Law and International Treaties. Unauthorized 6 reproduction or.distribution of this AW' l Jocument,'or any portion of it, a ay.result in severe civil and criminal penalties; and will be prosecuted to the. maximum extent possible under the law. This documentwas produced byAIA software at 13:52:51 on 11/12/2015 under order No.8143844491_1 which expires on 02/0112016, and is not for resale. User N otes: (947285321) VOLUME1 01 1000 Summary October 2015 4 01 22 00 Unit Prices October 2015 3 01 23 00 Alternates October 2015 3 01 2500 Substitution Procedures October 2015 3 01 26 00 Contract Modification Procedures October 2015 3 01 9-900 Payment Procedures October 2015 5 01 3100 Project Management and Coordination October 2015 7 01 3300 Submittal Procedures October 2015 8 01.40 00 _ QualityRequirements October 2015 8 _ 01 5000 Temporary Facilities and Controls October 2015 10 Init. AIA Document A101 TM — 2007. Copyright ©1915, 1918, 1925, 1937 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA° bocument is protected by U.$: Copyright Law and International Treaties. Unauthorized 6 reproduction or.distribution of this AW' l Jocument,'or any portion of it, a ay.result in severe civil and criminal penalties; and will be prosecuted to the. maximum extent possible under the law. This documentwas produced byAIA software at 13:52:51 on 11/12/2015 under order No.8143844491_1 which expires on 02/0112016, and is not for resale. User N otes: (947285321) 01 7300 Execution October 2015 9 01 7700 Closeout Procedures October 2015 6 01 7823 Operation and Maintenance Data October 2015 8 01 7839 Project Record Documents October 2015 3 01 7900 Demonstration and Training October 2015 6 03 30 00 Cast -In -Place Concrete October 2015 20 04 20 00 Unit Masonry October 2015 19 04 21 13 Brick Masonry October 2015 15 04 22 00 Concrete Unit Masonry October 2015 13 04 72 00 Cast Stone Masonry October 2015 8 05 1200 Structural Steel Framing October 2015 11 05 21 00 Steel Joist Framing October 2015 6 05 31 00 Steel Decking October 2015 6 05 40 00 Cold -Formed Metal Framing October 2015 9 05 50 00 Metal Fabrications October 2015 11 0551 11 Alternating Tread Devices October 2015 4 0553 13 Prefabricated Metal Canopies October 2015 3 06 06 60 Translucent Panel Material October 2015 9 06 1000 Rough Carpentry October 2015 7 06 1600 Sheathing October 2015 7 06 20 23 Interior Finish Carpentry October 2015 6 06 41 13 Wood -Veneer -Faced Architectural Cabinets October 2015 8 0641 16 Plastic -Laminate -Faced Architectural Cabinets October 2015 8 07 21 00 Thermal Insulation October 2015 5 07 25 00 Weather Barriers October 2015 2 07 26 30 Spray Polyurethane Foam Insulating Air Barrier System October 2015 9 0741 16 Standing -Seam Metal Roof Panels October 2015 10 074213 Formed Metal Wall Panels October 2015 9 07 43 23 Metal Composite Material Wall Panels October 2015 9 07 53 23 Ethylene -Propylene -Diene -Monomer (EPDM) Roofing October 2015 12 07 62 00 Sheet Metal Flashing and Trim October 2015 12 07 72 00 Roof Accessories October 2015 7 07 92 00 Joint Sealants October 2015 8 079219 AcodsticaI Joint Sealants October 2015 4 08 1113 Hollow Metal Doors and Frames October 2015 10 08 1416 Flush Wood Doors October 2015 7 0831 13 Access Doors and Frames October 2015 4 08 32 13 Aluminum Sliding Glass Doors October 2015 6 08 33 26 Overhead Coiling Grilles October 2015 6 0841 13 Aluminum -Framed Entrances and Storefronts October 2015 9 08 44 13 Glazed Aluminum Curtain Walls October 2015 9 08 71 00 Door Hardware October 2015 30 08 8000 Glazing October 2015 10 08 8300 Mirrors October 2015 5 088710 Window Film October 2015 4 092216 Non -Structural Metal Framing October 2015 7 09 29 00 Gypsum Board October 2015 8 09 30 00 Tile October 2015 10 09 51 13 Acoustical Panel Ceilings October 2015 7 09 65 13 Resilient Base and Accessories October 2015 5 0965 16 Linoleum Floor Coverings October 2015 7 09 68 13 Tile Carpeting October 2015 9 09 72 00 Wall Covering October 2015 5 09 91 13 Exterior Painting October 2015 7 09 91 23 Interior Painting October 2015 12 09 93 00 Staining and Transparent Finishing October 2015 6 0996-09--- High -Performance Coatings October 2015 11 Init. AIA Document A10VII-2007. Copyright©1916, 1916, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This RIA° Document Is protected by.U,S. Copyright Law and International Treaties. Unauthorized 7 reproduction or distribution of this AIA° Document; or any portion of It; may result in severe civil and criminal penalties, and will be prosecuted.to the maximum extent possible under the law..This document was produced by AIA software at 13:52:51 on 11A2/2015 under order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) 10 1100 Visual Display Surfaces October 2015 3 101419 Dimensional Letter Signage October 2015 8 10 14 23 Signage October 2015 7 1021 19 Plastic Toilet Compartments October 2015 6 10 22 39 Folding Panel Partitions October 2015 8 10 26 00 Wall and Door Protection October 2015 3 10 28 00 Toilet and Bath Accessories October 2015 9 10 44 13 Fire Protection Cabinets October 2015 4 10 75 00 Flagpoles October 2015 3 113100 Residential Appliances October 2015 3 11 5100 Library Equipment October 2015 4 11 5213 Projection Screens October 2015 6 122413 Roller Window Shades October 2015 6 12 36 61 Simulated Stone Countertops October 2015 4 12 93 00 Site Accessories October 2015 3 31 1000 Site Clearing October 2015 4 31 20 00 Earth Moving October 2015 14 312219 Finish Grading October 2015 2 32 1313 Concrete Paving October 2015 3 321413 Precast Concrete Unit Paving October 2015 6 32 31 13 Chain Link Fences and Gates October 2015 8 32 84 00 Underground Sprinkler System October 2015 10 32 92 00 Turf and Grasses October 2015 8 32 93 00 Furnishing and Planting of Plant Materials October 2015 9 33 41 00 Storm Utility Piping October 2015 7 33 46 00 Subdrainage Systems October 2015 3 AIA Document A1017m — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Init. Institute of Architects. All rights reserved. WARNING: This AIA° Document is protected by U,S. Copyright, Law and International Treaties. Unauthorized 8 reproduction or distribution of this AIA° Document, or any portion of it, may result m severe civil and criminal penalties, and will be prosecuted to the maximum extent possible cinder the law. This document was produced by AIA software at 13:52:51 on 11/12/2015 under Order No. 8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) VOLUME 2 21 0500 Basic Fire Protection Requirements October 2015 17 21 05 13 Electrical Requirements for Fite Protection Equipment October 2015 2 21 0519 Fire Protection Gauges October 2015 3 21 0529 Hangers and Supports for Fire Protection System October 2015 5 21 0553 Identification for Fire Protection System October 2015 3 21 13 13 Fire Protection System October 2015 9 22 05 00 Basic Plumbing Requirements October 2015 19 2205 13 Electrical Requirements for Plumbing Equipment October 2015 9 22 05 19 Plumbing Meters and Gauges October 2015 5 22 05 29 Hangers and Supports for Plumbing System October 2015 15 22 05 53 Identification for Plumbing Piping October 2015 4 22 07 16 Plumbing Equipment Insulation October 2015 4 22 07 19 Plumbing Piping Insulation October 2015 6 22 10 00 Plumbing Piping October 2015 11 2211 13 Facility Water Distribution Piping October 2015 9 22 11 19 Plumbing Specialties October 2015 4 22 30 00 Plumbing Equipment October 2015 6 22 40 00 Plumbing Fixtures October 2015 5 23 0500 Basic HVAC Requirements October 2015 23 23 05 13 Electrical Requirements for Mechanical Equipment October 2015 8 23 05 19 HVAC Meters and Gauges October 2015 4 23 0529 HVAC Hangers and Supports October 2015 15 23 05 53 HVAC Identification October 2015 3 23 05 93 Testing, Adjusting and Balancing October 2015 9 230713 Ductwork Insulation October 2015 4 23 07 19 HVAC Piping Insulation October 2015 4 23 09 00 Digital Control System October 2015 2 23 09 01 Instruments and Control Elements October 2015 8 23 09 93_ _ Sequence of Operation October 2015 AIA Document A1017m — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Init. Institute of Architects. All rights reserved. WARNING: This AIA° Document is protected by U,S. Copyright, Law and International Treaties. Unauthorized 8 reproduction or distribution of this AIA° Document, or any portion of it, may result m severe civil and criminal penalties, and will be prosecuted to the maximum extent possible cinder the law. This document was produced by AIA software at 13:52:51 on 11/12/2015 under Order No. 8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) 2321 13 Hydronic Piping October 2015 3 23 23 00 Refrigerant Piping and Specialties October 2015 4 2331 13 Ductwork October 2015 16 23 31 16 Ductwork Accessories October 2015 5 23 3600 Air Terminal Units October 2015 3 23 37 00 Air Outlets and Inlets October 2015 3 23 5100 Breechings, Chimneys and Stacks October 2015 4 23 74 13 Dedicated Outdoor Air System October 2015 8 23 8127 Variable Refrigerant Flow System October 2015 22 23 8239 Terminal Heat Transfer October 2015 3 238413 Gas -Fired Evaporative Steam Humidification System October 2015 6 26 05 00 Electrical General Provisions October 2015 9 26 05 01 Basic Materials and Methods October 2015 9 26 05 19 Conductors October 2015 5 26 05 26 Grounding System October 2015 4 26 05 33 Raceways October 2015 6 26 24 16 Panelboards October 2015 8 26 27 26 Wiring Devices October 2015 5 262913 Motor Controllers October 2015 5 26 51 00 Lighting October 2015 8 27 00 00 Telecommunications Cable Plant October 2015 10 28 31 11 Addressable Fire Alarm System October 2015 18 § 9.1.5 The Drawings: (Either list the Dratvings here or refer to an exhibit attached to this Agreement.) Number Title Date G0.00 Title Sheet & Drawing Index October 9, 2015 G0.01 General Notes, Symbols & Abbreviations October 9, 2015 G0.10 Code Compliance Plan October 9, 2015 C1.01 Water Service Plan October 9, 2015 L1.01 Existing Conditions October 9, 2015 L2.01 Site Layout Plan October 9, 2015 L2.02 Pavement Jointing Plan October 9, 2015 L3.01 Site Grading and Storm Sewer Plan October 9, 2015 L4.01 Site Planting Plan — Shrub and Perennials October 9, 2015 L4.02 Site Planting Plan — Turf Grasses October 9, 2015 L5.01 Site Irrigation Plan October 9, 2015 L6.01 Site Details October 9, 2015 L6.02 Dumpster Enclosure October 9, 2015 A0.00 Wall Type Schedule & Details October 9, 2015 A1,11 First Floor Plan October 9, 2015 A1.21 First Floor Reflected Ceiling Plan October 9, 2015 A1.30 Roof Plan October 9, 2015 A1.31 Roof Plans & Details October 9, 2015 A2.10 Exterior Elevations October 9, 2015 A2.11 Exterior Elevations October 9, 2015 A2.12 Exterior Brick Elevations October 9, 2015 A2.13 Exterior Perspectives October 9, 2015 A3.10 Building Cross Sections October 9, 2015 A3.11 Building Cross Sections October 9, 2015 A4.10 Wall Sections October 9, 2015 A4.11 Wall Sections October 9, 2015 A4.12 Wall Sections October 9, 2015 A4.13 Wall Sections October 9, 2015 A4.-14___ Wall Sections- October 9, 2015 AIA Document A101"1-2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, `1953,1967,1974, 1977, 1987, 1991, 1997 and 2007 by The American Inst. institute of Architects. Ali rights reserved. WARNING: This AIA° Document is protected by U.S Copyright Law and International Treaties. Unauthorized 9 reproduction or distribution of this AIA' Document, or any.portfon of it, may result in severe civil and criminal penalties, and will be prosecuted to the t maximum extent possible under the law. This documentwas produced byAlA software at 13:52:51 on 11/12/2015 under Order No.8143844491 1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) A6.10 Enlarged Restroom Plans, Elevations & Schedules October 9, 2015 A6.11 Enlarged Plans, Interior Elevations & Schedules October 9, 2015 A6.20 Interior Elevations October 9, 2015 A6.21 Interior Elevations October 9, 2015 A6.22 Interior Elevations October 9, 2015 A6.23 Interior Elevations October 9, 2015 A6.30 Casework Sections October 9, 2015 A6.31 Interior Details October 9, 2015 A6.40 Door Schedule, Door Types, Frame Types October 9, 2015 A6.50 Frame Types October 9, 2015 A8.10 Section Details October 9, 2015 A8.11 Section & Plan Details October 9, 2015 A8.12 Entrance Column Base & Seat Wall Details October 9, 2015 F1.11 First Floor Finishes Plan, Schedule, & Details October 9, 2015 F1,12 Signage Plan & Details October 9, 2015 F1.13 Signage Details October 9, 2015 S0.00 Structural Notes October 9, 2015 S1.01 Footing & Foundation Plan October 9, 2015 S2.01 Roof Framing Plan October 9, 2015 S2.02 High Roof Framing Plans & Elevated Slab Reinforcing Plan October 9, 2015 53.01 Column Schedule & Baseplate Details October 9, 2015 53.02 Foundation Details October 9, 2015 S4.01 Framing Details October 9, 2015 54.02 Framing Details October 9, 2015 S5.01 Typical Exterior Stud Wall Framing & CMU Details October 9, 2015 M0.00 Mechanical Abbreviations, Symbols & Notes October 9, 2015 M1.01 First Floor HVAC Plan October 9, 2015 M1.02 Mechanical Roof Plan October 9, 2015 M2.01 Underfloor Piping Plan October 9, 2015 M2.02 First Floor Piping Plan October 9, 2015 M3.01 First Floor Fire Suppression Plan October 9, 2015 M3.02 Penthouse Fire Suppression Plan October 9, 2015 M3.03 Fire Suppression Piping Schematic October 9, 2015 M4.01 Enlarged Mechanical Rooms & Sections October 9, 2015 M4.02 Enlarged Mechanical Rooms & Sections October 9, 2015 M4.03 Mechanical Sections October 9, 2015 M5.01 Piping Riser Diagrams October 9, 2015 M5.02 Mechanical Schematics October 9, 2015 M5.03 Mechanical Schematics October 9, 2015 M6.01 Mechanical Details October 9, 2015 M6.02 Mechanical Details October 9, 2015 M7.01 Mechanical Schedules October 9, 2015 M7.02 Mechanical Schedules October 9, 2015 E0.00 Electrical Abbreviations, Symbols Legend & General Notes October 9, 2015 E0.01 Electrical Site Utilities Plan October 9, 2015 E1.01 First Floor & Penthouse Lighting Plan October 9, 2015 E2.01 First Floor Power & Auxiliary Systems Plan October 9, 2015 E2.02 First Floor & Penthouse Power & Auxiliary Systems Plan — October 9, 2015 Mechanical Connections E3.01 Electrical One Line Diagram, Details & Schedules October 9, 2015 E4.01 Electrical Schedules October 9, 2015 T1.01 First Floor Telecommunications Plan October 9, 2015 T2.01 Telecommunications Riser & Details October 9, 2015 AIA Document A101Tm — 2007. Copyright ©1915, 1918, 1925, 1937, 1961, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Init. Institute of Architects. All rights reserved. WARNING: This, RIA® Document is: protected by U.S. Copyright Late and International Treaties: Unauthorized 10 reproduction or distribution of this RIA° Document, or any portion of It, may result in severe civil and criminal penalties, and will be: prosecuted to the mauimum extent possible under the law. This documentwas produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) § 9.1.6 The Addenda, if any: Number Date Pages Addendum No. 1 October 23, 2015 6 Addendum No. 2 October 30, 2015 17 Portions of Addenda relating to bidding requirements are not part of the Contract Documents unless the bidding requirements are also enumerated in this Article 9. § 9.1.7 Additional documents, if any, forming part of the Contract Documents: .1 AIA Document E201T1' 2007, Digital Data Protocol Exhibit, if completed by the parties, or the following: .2 Other documents, if any, listed below: (List here any additional documents that are intended to form part of the Contract Documents. AIA Document A201 2007 provides that bidding requirements such as advertisement or invitation to bid, Instructions to Bidders, sample forms and the Contractor's bid are not part of the Contract Documents unless enumerated in this Agreement. They should be listed here only if intended to be part of the Contract Documents.) Invitation for Bids (Form RD 1924-5) Instructions to Bidders, AIA A701-1997 Attachment to the Instructions to Bidders (RD Instruction 1924-A, Guide 27, Attachment 2) Bid Form Bid Bond Compliance Statement (From RD 400-6) Payment Bond Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion — Lower Tier Covered Transactions (Form AD 1048) Disclosure of Lobbying Activities (SF -LLL) Certificated for Contracts, Grants and Loans (RD Instruction 1940-Q, Exhibit A-1) ARTICLE 10 INSURANCE AND BONDS The Contractor shall purchase and maintain insurance and provide bonds as set forth in Article 11 of AIA Document A201-2007. (State bonding requirements, if any, and limits of liability for insurance required in Article 11 of AIA Document A201-2007) Type of insurance or bond See Project Manual, Supplementary Conditions, Section 00 73 00, Article 11 Init. AIA Document A101Tm — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. Ali rights reserved. WARNING: This AIAA'3 Document is protected by U.S. Copyright Law and International Treaties: Unauthorized 1 reproduction or distribution of this AIA® Docurnent, or any portion of it, may result in.severe civil and criminal penalties, and will be prosecuted tothe t maximum:extent possible under the law. This documentwas produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User N otes; (947285321) This Agreement entered into as of the day and year first written above. IN WITNESS WHEREOF, the parties hereto have executed, or caused to be executed by their duly authorized officials, this Agreement in duplicate on the respective dates indicated below: ATTEST:Quuc-c 94"._ Type Name -:().b►1r.-}6 S Title ').E.t- ;d x1 Date la -Ito -15 Title II� �` l� Date I AGENCY CO CURREN By (Table del ted_ Type Name ric1' 1?6M,4421® Title L)Sr>A Fl> AacOrrver Date JA 14 16 OW NE . By .� Type N Title ViTsidsnt Date 1A • /& • /S �ON CTOR: Type Name 11346*1 '(Title 1119 ISM Date 17 V- The concurrence so evidenced by the Agency shall in no way commit the Agency to render financial assistance to the Owner and is without liability to the Agency for any payment hereunder, but in the event such assistance is provided, the concurrence shall signify the provisions of this Agreement are consistent with Agency requirements. Init. AIA Document A101TM' — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1968, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING* This Ale Document is protected by U.$. Copyright Law and International Treaties. Unauthorized 12 reproduction or distribution of this AIA' Document, or any portion of it, may result m severe civil and criminal penalties, and Mil be prosecuted to the maximum extent poi;sible under the law, This documentwas produced byAlAsoftware at 13:52:51 on 11/12/2015 under Order No.8143844491 1 which expires on 02/01/2016, and. is not for resale. User Notes: (947285321) Additions and Deletions Report for AIA Document A 101 TM —2007 This Additions and Deletions Report, as defined on page 1 of the associated document, reproduces below all text the author has added to the standard form AIA document in order to complete it, as well as any text the author may have added to or deleted from the original AIA text. Added text is shown underlined. Deleted text is indicated with a horizontal line through the original AIA text. Note: This Additions and Deletions Report is provided for information purposes only and is not incorporated into or constitute any part Of the associated AIA document. This Additions and Deletions Report and Its associated document were generated simultaneously by AIA software at 13:52:51 on 11/12/2015. AGREEMENT made as of the Tenth day of November in the year Two Thousand Fifteen Blair Public Library Foundation P.O. Box 743 Blair, Nebraska 68008 The Weitz Company 8715 South 121st Street LaVista, Nebraska 68128 Blair Public Library and Technology Center Building Package The Clark Enersen Partners 1010 Lincoln Mall, Suite 200 Lincoln. Nebraska 68508 PAGE § 3.1 The date of commencement eft"e Work s"e" " bel de r+_tie date ,ed :n e n„ee o ,.reeeed issued by the Ownerm�-vt—�coTcaro�i3-nii[ac .. r . . f.titmva: (insert the date f eommeneement if it differs fii•eFn the date _of this Agreement •eement o if .. 1ieable state that the date will be fNed in a ..,.t: ee to preeeed.`shall be contained in the Notice to Proceed. The Contractor shall achieve Substantial Completion of the entire Work not later than July 1, 2017. Additions and Deletions Report for AIA Document A101TM — 2007. Copydght ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963,1$67,1974,1977,1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA° Document is protected by U.S. Copyright Law and International Treaties: Unauthorized ;reproduction or distribution of this AIA" Document, or any portion.of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 13:62:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01%2016, and is not for resale. User Notes: (947285321) If the work is not substantially complete on or before this date or within this period of time, or extension thereof granted by the Owner, damage will be sustained by the Owner and that it is and will be impracticable and extremely difficult to fix the actual damage which the Owner will sustain in the event of and by reason of such delays. The Contractor shall pay to the Owner liquidated damages in the sum of $0.00 for each calendar day of delay. Any that may be due the Owner as liquidated damages may be deducted from any monies due or to become due the Contractor under the Contract or may be collected from the Contractor's surety. Portion of Wer SubstantialCompletion Date PAGE § 4.1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor's performance of the Contract. The Contract Sum shall be Four Million Two Hundred Twenty-two Thousand Five Hundred Dollars and Zero Cents ($ 4,222,500.00 ), subject to additions and deductions as provided in the Contract Documents. Base bid: $4,075,000.00 A-3: +$17,500.00 L -l: +$20,000.00 E-1: +$110,000.00 Total: $4,222,500.00 ltefn Prise Per Unit ($0:08) Item Price Per Unit ($0.00) Unit Price No. 1 39.00/SY Unit Price No. 2 $4.50/SF Unit Price No. 3 $260.00/SF ltern Prlee § 5.1.3 Provided that an Application for Payment is received by the Architect not later than the Thirtieth day of a month, the Owner shall make payment of the certified amount to the Contractor not later than the Thirtieth day of the following month. If an Application for Payment is received by the Architect after the application date fixed above, payment shall be made by the Owner not later than Forty-five ( 45) days after the Architect receives the Application for Payment. PAGE 4 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the Contract Sum allocated to that portion of the Work in the schedule of values, less retainage of pereent( e'�riiingl final d ♦ t• f east to the Oyffief .. f eha„,.e..:„ the \x7...1. a .nts «et i f d:spHte shall be ineluded as provided in Seetio 7.3.9 of ALA_nveument-TrMINr 2007f general Conditions efzrah Gentret for GenstfaegewTen Dercent ( 10.00 %). Additions and Deletions Report for AIA Document A101TM —2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This Ale Document Is,,protected by U;S. Copyright Lamy and 2 International Treaties. Unauthorised reproduction or distribution of this=Aie Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This documentwas produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01(2016, and is not for resale. User Notes: (947285321) Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed eonstrHetion (or, °r .Tapes; ed in advanee by the Owner, suitably ed off -the site at a le t' agreed upon ,..:ting) less. retainage a pereent (—construction, less retainage of Ten percent (10.00 %); The amount retained shall be 10% of the value of Work until 50% of the Work has been completed. At 50% completion further partial payments shall be made in full to the Contractor and no additional amounts may be retained unless the Architect certifies that the Work is not proceeding satisfactorily, but amounts previously retained shall not be paid to the Contractor. At 50% completion or any time thereafter when the progress of the Work is not satisfactory additional amounts may be retained but in no event shall the total retainage be more than 10% of the value of Work completed. PAGE [ X I Litigation in a court of competent jurisdiction 6,00 %per annum Rodney Storm Blair City Administrator 218 South 16th Street Blair, Nebraska 68008 Brian Malhendorf The Weitz Company 8715 South 121st Street LaVista, Nebraska 68128 PAGE 6 & 8.6,1 This Agreement shall not become effective until concurred in writing by the Agency. Such concurrence shall be evidences by the signature of a duly authorized representative of the Agency in the space provided at the end of this Attachment to the Agreement The concurrence so evidenced by the Agency shall in no way commit the Agency to render financial assistance to the Owner and is without liability to the Agency for any payment thereunder, but in the event such assistance is provided the concurrence shall signify the provisions of this Agreement are consistent with Agency requirements. Attachment to the Standard Form of Agreement Between Owner and Contractor General Conditions of the Contract for Construction, AIA 201-2007 Attachment to the General Conditions of the Contract for Construction (RD Instruction 1942-A, Guide 27, Attachment 4) Special Conditions Proiect Manual Advertisement for Bids October 2015 2 Proiect Manual Instructions -to- Bidders October 2015 1 Additions and Deletions Report for AIA Document A101T"r —2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, i991,1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This Ate Document is protected by U.S. Copyright Law and 3 International Treaties. Unauthorized reproduction or distribution of this Ale Document, or any portion of! t, may. result In severe civil and criminal penalties, and will be prosecuted to the maximum extent passible under the law. This documentwas produced by AIA software at 13:62:5166 11/12/2015 under Order No.8143844491_i which expires on 02/01/2016, and is not for resale. User Notes: (947285321) Project Manual Supplementatti Instructions to Bidders October 2015 1 Project Manual Geotechnical Data December 15, 2014 39 Proiect Manual Bid Form October 2015 3 Project Manual General Conditions October 2015 1 Project Manual Supplementary Conditions October 2015 15 Additions and Deletions Report for AIA Document A1011m — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Documentis protected by U.S. CopyfightLaWand 4 International Treaties, Unadthorized reproduotionor distribution of this, AIA°Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This documentwas produced by AIA software at 13:52:51 on 11/1212016 nd uer Order No.8143844491_1 which expires on'0210112016, and is not for resale. User N otes: (947285321) VOLUME 1 01 1000 Summary October 2015 4 01 2200 Unit Prices October 2015 3 01 23 00 Alternates October 2015 3 01 2500 Substitution Procedures October 2015 3 01 26 00 Contract Modification Procedures October 2015 3 01 2900 Payment Procedures October 2015 5 01 3100 Proiect Management and Coordination October 2015 7 01 3300 Submittal Procedures October 2015 8 01 4000 Quality Requirements October 2015 8 01 5000 Temporary Facilities and Controls October 2015 10 01 7300 Execution October 2015 9 01 77 00 Closeout Procedures October 2015 6 01 7823 Operation and Maintenance Data October 2015 8 01 78 39 Project Record Documents October 2015 3 01 7900 Demonstration and Training October 2015 6 03 30 00 Cast -In -Place Concrete October 2015 20 04 20 00 Unit Masonry October 2015 19 04 21 13 Brick Masonry October 2015 15 04 22 00 Concrete Unit Masonry October 2015 13 04 72 00 Cast Stone Masonry October 2015 8 05 1200 Structural Steel Framint; October 2015 11 05 21 00 Steel Joist Framing October 2015 6 053100 Steel Decking October 2015 6 05 40 00 Cold -Formed Metal Framing October 2015 9 05 50 00 Metal Fabrications October 2015 11 05 51 11 Alternating Tread Devices October 2015 4 0553 13 Prefabricated Metal Canopies October 2015 3 06 06 60 Translucent Panel Material October 2015 9 06 10 00 Rough Carpentry October 2015 7 06 1600 Sheathing October 2015 7 06 20 23 Interior Finish Carpentry October 2015 6 0641 13 Wood -Veneer -Faced Architectural Cabinets October 2015 8 06 41 16 Plastic -Laminate -Faced Architectural Cabinets October 2015 8 07 21 00 Thermal Insulation October 2015 5 07 25 00 Weather Barriers October 2015 2 07 26 30 Spray Polyurethane Foam Insulating Air Barrier System October 2015 9 07 41 16 Standing -Seam Metal Roof Panels October 2015 10 074213 Formed Metal Wall Panels October 2015 9 07 43 23 Metal Composite Material Wall Panels October 2015 9 07 53 23 Ethylene -Propylene -Diene -Monomer (EPDM) Roofing October 2015 12 07 62 00 Sheet Metal Flashing and Trim October 2015 12 07 72 00 Roof Accessories October 2015 7 07 92 00 Joint Sealants October 2015 8 079219 Acoustical Joint Sealants October 2015 4 08 1113 Hollow Metal Doors and Frames October 2015 10 08 1416 Flush Wood Doors October 2015 7 08 31 13 Access Doors and Frames October 2015 4 08_3213 _ Aluminum Sliding Glass Doors October 2015 6 Additions and Deletions Report for AIA Document A1011m — 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Documentis protected by U.S. CopyfightLaWand 4 International Treaties, Unadthorized reproduotionor distribution of this, AIA°Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This documentwas produced by AIA software at 13:52:51 on 11/1212016 nd uer Order No.8143844491_1 which expires on'0210112016, and is not for resale. User N otes: (947285321) 08 33 26 Overhead Coiling Grilles October 2015 6 08 41 13 Aluminum -Framed Entrances and Storefi•onts October 2015 9 084413 Glazed Aluminum Curtain Walls October 2015 9 08 71 00 Door Hardware October 2015 30 08 80 00 Glazin October 2015 10 08 83 00 Mirrors October 2015 5 08 8710 Window Film October 2015 4 092216 Non -Structural Metal Framing October 2015 7 09 29 00 Gypsum Board October 2015 8 09 30 00 Tile October 2015 10 09 51 13 Acoustical Panel Ceilings October 2015 7 096513 Resilient Base and Accessories October 2015 5 09 65 16 Linoleum Floor Coverings October 2015 7 096813 Tile Carpeting October 2015 9 09 72 00 Wall Covering October 2015 5 09 91 13 Exterior Painting October 2015 7 09 91 23 Interior Painting October 2015 12 09 93 00 Staining and Transparent Finishing October 2015 6 09 96 00 High -Performance Coatings October 2015 11 10 1100 Visual Display Surfaces October 2015 3 101419 Dimensional Letter Signage October 2015 8 10 14 23 Si age October 2015 7 10 21 19 Plastic Toilet Compartments October 2015 6 10 22 39 Folding Panel Partitions October 2015 8 10 26 00 Wall and Door Protection October 2015 3 10 28 00 Toilet and Bath Accessories October 2015 9 104413 Fire Protection Cabinets October 2015 4 10 75 00 Flagpoles October 2015 3 113100 Residential Appliances October 2015 3 115100 Librar�Eguipment October 2015 4 11 5213 Proiection Screens October 2015 6 122413 Roller Window Shades October 2015 6 12 36 61 Simulated Stone Countertops October 2015 4 12 93 00 Site Accessories October 2015 3 31 1000 Site Clearing October 2015 4 31 20 00 Earth Moving October 2015 14 312219 Finish Grading October 2015 2 32 13 13 Concrete Paving October 2015 3 321413 Precast Concrete Unit Paving October 2015 6 3231 13 Chain Link Fences and Gates October 2015 8 32 84 00 Underground Sprinkler System October 2015 10 32 92 00 Turf and Grasses October 2015 8 32 93 00 Furnishing and Planting of Plant Materials October 2015 9 33 41 00 Storm Utilit�Prping October 2015 7 33 46 00 Subdrainage Systems October 2015 3 VOLUME 2 21 0500 Basic Fite Protection Requirements October 2015 17 21 0513 Electrical Requirements for Fite Protection Equipment October 2015 2 21 0519 Fire Protection Gauges October 2015 3 21 0529 Hangers and Supports for Fire Protection System October 2015 5 21 0553 Identification for Fire Protection System October 2015 3 21 1313 Fire Protection System October 2015 9 22 05 00 Basic Plumbing Requirements October 2015 19 22 05 13 Electrical Requirements for Plumbing Equipment October 2015 9 22 05 19 Plumbing Meters and Gauges October 2015 5 _ 22-05-29- . -._ -- _ -- -- — — - — - Hangers -and Supports for Plumbing System- -- - October 2015 15 Additions and Deletions Report for AIA Document A101T1' -- 2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA° Document is protected by U.S. C6pyrlght Lal✓ and 5 Interriationai Treaties. Unauthorized' reproduction or44stribution of this Ale Document, or any portion of it, may resuitIn severe civil and criminal penalties, and will be,proseciited to the maximum extent possible under the- law. This document was produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) PAGE 9 22 05 53 Identification for Plumbing Piping October 2015 4 220716 Plumbing Equipment Insulation October 2015 4 220719 Plumbing Piping Insulation October 2015 6 22 10 00 Plumbing Piping October 2015 11 2211 13 Facility Water Distribution Piping October 2015 9 22 11 19 Plumbing Specialties October 2015 4 22 30 00 Plumbing Equipment October 2015 6 22 40 00 Plumbing Fixtures October 2015 5 23 05 00 Basic HVAC Requirements October 2015 23 23 05 13 Electrical Requirements for Mechanical Equipment October 2015 8 23 05 19 HVAC Meters and Gauges October 2015 4 23 05 29 HVAC Hangers and Supports October 2015 15 23 05 53 HVAC Identification October 2015 3 23 05 93 Testing, Adjusting and Balancing October 2015 9 230713 Ductwork Insulation October 2015 4 230719 HVAC Piping Insulation October 2015 4 23 09 00 Digital Control System October 2015 2 23 09 01 Instruments and Control Elements October 2015 8 23 09 93 Sequence of Operation October 2015 6 23 21 13 Hydronic Piping October 2015 3 23 23 00 Refrigerant Piping and Specialties October 2015 4 23 31 13 Ductwork October 2015 16 23 31 16 Ductwork Accessories October 2015 5 23 36 00 Air Terminal Units October 2015 3 23 37 00 Air Outlets and Inlets October 2015 3 23 51 00 Breechings, Chimneys and Stacks October 2015 4 237413 Dedicated Outdoor Air System October 2015 8 238127 Variable Refrigerant Flow System October 2015 22 23 8239 Terminal Heat Transfer October 2015 3 23 8413 Gas -Fired Evaporative Steam Humidification System October 2015 6 26 05 00 Electrical General Provisions October 2015 9 26 05 01 Basic Materials and Methods October 2015 9 26 05 19 Conductors October 2015 5 26 05 26 Groundina System October 2015 4 26 05 33 Raceways October 2015 6 262416 Panelboar•ds October 2015 8 26 27 26 Wiring Devices October 2015 5 262913 Motor Controllers October 2015 5 265100 Li tin October 2015 8 27 00 00 Telecommunications Cable Plant October 2015 10 28 31 11 Addressable Fire Alarm System October 2015 18 G0.00 Title Sheet & Drawing Index October 9, 2015 130.01 General Notes, S=bols & Abbreviations October 9, 2015 G0.10 Code Compliance Plan October 9, 2015 C1.01 Water Service Plan October 9, 2015 L1.01 Existing Conditions October 9, 2015 L2.01 Site Layout Plan October 9, 2015 L2.02 Pavement Jointing Plan October 9, 2015 L3.01 Site Grading and Storm Sewer Plan October 9, 2015 L4.01 Site Planting Plan — Shrub and Perennials October 9, 2015 L4.02 Site Planting Plan — Turf Grasses October 9, 2015 L5.01 Site Irrigation Plan October 9, 2015 L6.01 Site Details October 9, 2015 16.02 — Dumpster Enclosure October 9,-2015 Additions and Deletions Report for AIA Document A101TM —2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document Is protected by UrS. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this _AIA° Document, or any portion of it, may result in severe civil and *criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) A0.00 Wall Type Schedule & Details- October 9, 2015 A1.11 First Floor Plan October 9, 2015 A1.21 First Floor Reflected Ceiling Plan October 9, 2015 A1.30 Roof Plan October 9, 2015 A1.31 Roof Plans & Details October 9, 2015 A2.10 Exterior Elevations October 9, 2015 A2.11 Exterior Elevations October 9, 2015 A2.12 Exterior Brick Elevations October 9, 2015 A2.13 Exterior Perspectives October 9, 2015 A3.10 Building Cross Sections October 9, 2015 A3.11 Building Cross Sections October 9, 2015 A4.10 Wall Sections October 9, 2015 A4.11 Wall Sections October 9, 2015 A4.12 Wall Sections October 9, 2015 A4.13 Wall Sections October 9, 2015 A4.14 Wall Sections October 9, 2015 A6.10 Enlarged Restroom Plans, Elevations & Schedules October 9, 2015 A6.11 Enlarged Plans, Interior Elevations & Schedules October 9, 2015 A6.20 Interior Elevations October 9, 2015 A6.21 Interior Elevations October 9, 2015 A6.22 Interior Elevations October 9, 2015 A6.23 Interior Elevations October 9, 2015 A6.30 Casework Sections October 9, 2015 A6.31 Interior Details October 9, 2015 A6.40 Door Schedule, Door Types, Frame Types October 9, 2015 A6.50 Frame Types October 9, 2015 A8.10 Section Details October 9, 2015 A8.11 Section & Plan Details October 9, 2015 A8.12 Entrance Column Base & Seat Wall Details October 9, 2015 Fill First Floor Finishes Plan, Schedule, & Details October 9, 2015 F1, 12 Signage Plan & Details October 9, 2015 F1.13 Signage Details October 9, 2015 S0.00 Structural Notes October 9, 2015 51.01 Footing & Foundation Plan October 9, 2015 52.01 Roof Framing Plan October 9, 2015 52.02 High Roof Framing Plans & Elevated Slab Reinforcing Plan October 9, 2015 S3.01 Column Schedule & Baseplate Details October 9, 2015 S3.02 Foundation Details October 9, 2015 S4.01 Framing Details October 9, 2015 54.02 Framing Details October 9, 2015 S5.01 Typical Exterior Stud Wall Framing & CMU Details October 9, 2015 M0.00 Mechanical Abbreviations, Symbols & Notes October 9, 2015 M1.01 First Floor HVAC Plan October 9, 2015 M1.02 Mechanical Roof Plan October 9, 2015 M2.01 Underfloor Piping Plan October 9, 2015 M2.02 First Floor Piping Plan October 9, 2015 M3.01 First Floor Fire Suppression Plan October 9, 2015 M3.02 Penthouse Fire Suppression Plan October 9, 2015 M3.03 Fire Suppression Piping Schematic October 9, 2015 M4.01 Enlarged Mechanical Rooms & Sections October 9, 2015 M4.02 Enlarged Mechanical Rooms & Sections October 9, 2015 M4.03 Mechanical Sections October 9, 2015 M5.01 Piping Riser Diagrams October 9, 2015 M5.02 Mechanical Schematics October 9, 2015 M5.03 Mechanical Schematics October 9, 2015 M6.01 Mechanical Details October 9, 2015 -M6.02 Moolianical -Details - - - - October 9,-2015 Additions and Deletions Report for AIA Document A1011m —2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This:Ale Docu'rr6nt Is protected by U.S. Copyright Lave and 7 In.tematioual Treaties. Unauthorized reproduction of distribution of this Ale Document, or any, portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_7 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) M7.01 Mechanical Schedules M7.02 Mechanical Schedules E0.00 Electrical Abbreviations, Symbols Legend & General Notes E0.01 Electrical Site Utilities Plan E1.01 First Floor & Penthouse Lighting Plan E2.01 First Floor Power & Auxiliary ystems Plan E2.02 First Floor & Penthouse Power & AuxiliarySystems Plan — Mechanical Connections E3.01 Electrical One Line Diagram, Details & Schedules E4.01 Electrical Schedules T1.01 First Floor Telecommunications Plan T2.01 Telecommunications Riser & Details October 9. 2015 October 9, 2015 October 9, 2015 October 9, 2015 October 9, 2015 October 9, 2015 October 9, 2015 October 9, 2015 October 9, 2015 October 9, 2015 October 9, 2015 Additions and Deletions Report for AIA Document A101 T"' —2007. Copyright ©1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All tights reserved. WARNING: This Ale Document is protected, by U.S. Copyright Law and $ International Treaties, Unauthorized reproduction or distribution of this AIA®Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to. the maximum ekient possible under the law. This documentwas produced by AIA software at 13;52:51 'on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, -and is not for resale. User Notes: (947285321) PAGE 11 Addendum No. I October 23, 2015 6 Addendum No. 2 October 30, 2015 17 Invitation for Bids (Form RD 1924-5) Instructions to Bidders, AIA A701-1997 Attachment to the Instructions to Bidders (RD Instruction 1924-A, Guide 27, Attachment 2) Bid Form Bid Bond Compliance Statement (From RD 400-6) Payment Bond Certification Regarding Debarment Suspension, Ineligibility and Voluntary Exclusion — Lower Tier Covered Transactions (Form AD 1048) Disclosure ofLobbying Activities (SF -LLL Certificated for Contracts, Grants and Loans (RD Instruction 1940-0, Exhibit A-1) Type of insuranGe-or-boM Limit of liability or bondamount( O.A Type of insurance or bond See Project Manual, Supplementary Conditions, Section 00 73 00, Article 11 Additions and Deletions Report for AIA Document A101T1' —2007. Ccpyright01915, 1918, 1926, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved.'WARNING: This AIA° Document'is protected by U.S. Copyright Law and 9 International Treaties. Unauthorized 'reproduction or distribution of this AIA® Document, or any portion of it, may result, in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible unifier the law. This document was produced by AIA software at 13:52:51 on 11/1212015 under Order No.8143844491_1 which expires on 02%01%2016, and is not for resale. User Notes: (947285321) This Agreement entered into as of the day and year first written above. IN WITNESS WHEREOF the parties hereto have executed, or caused to be executed by their duly authorized officials, this Agreement in duplicate on the respective dates indicated below: OWNER: ATTEST: By Type Name Type Name Title Title Date Date CONTRACTOR: ATTEST: By Type Name Type Name Title Title Date Date AGENCY CONCURRENCE: By Type Name Title Date The concurrence so evidenced b the he Agency shall in no way commit the Agency to render financial assistance to the Owner and is without liability to the Agency for anypUment hereunder, but in the event such assistance is provided, the concurrence shall signify the provisions of this Agreement are consistent with Agency requirements. Additions and Deletions Report for AIA Document A101 T1' — 2007. Copyright @ 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This MA' Document is protected by U.S. Copyright Law and 10 International Treaties. Unauthorized reproduction or distribution of this AIA° Document; or any portion of it, may resulfin severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2016, and is not for resale. User Notes: (947285321) Certification of Document's Authenticity AW Document D401Im — 2003 I, Joy Bullington, hereby certify, to the best of my knowledge, information and belief, that I created the attached final document simultaneously with its associated Additions and Deletions Report and this certification at 13:52:51 on 11/12/2015 under Order No. 8143844491_1 from AIA Contract Documents software and that in preparing the attached final document I made no changes to the original text of AIA® Document A10ITM — 2007, Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum, as published by the AIA in its software, other than those additions and deletions shown in the associated Additions and Deletions Report. (Signed) M+ ('Title) wwr N- (Dated) AIA Document D401 Tm — 2003. Copyright ©1992 and 2003 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA° Document, orany portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 13:52:51 on 11/12/2015 under Order No.8143844491_1 which expires on 02/01/2018, and is not for resale, User Notes: (947285321) Form Approved USDA OMB No. 0575-0018 R Form ]ZD 400-6 fRevorm 4 COMPLIANCE STATEMENT This statement relates to a proposed contract with (Name of borrotiber or grantee) who expects to finance the contract with assistance from either the Rural Housing Service (RHS), Rural Business -Cooperative Service (RBS), or the Rural Utilities Service (RUS) or their successor agencies, United States Department of Agriculture (whether by a loan, grant, loan insurance, guarantee, or other form of financial assistance). I am the undersigned bidder or prospective contractor, I represent that: 1. I Whave, ❑ have not, participated in a previous contract or subcontract subject to Executive Order 11246 (regarding equal employment opportunity) or a preceding similar Executive Order. 2. If I have participated in such a contract or subcontract,1 0 have, ❑ have not, filed all compliance reports that have been required to file in connection with the contract or subcontract. If the proposed contract is for $50,000 or more: or ❑ If the proposed nonconstruction contract is for $50,000 or more and 1 have 50 or more employees, I also represent that: I have, ❑ have not previously had contracts subject to the written affirmative action programs requirements of the Secretary of Labor. If I have participated in such a contract or subcontract, KI have, ❑ have not developed and placed on file at each establishment affirmative action programs as required by the rules and regulations of the Secretary of Labor. I understand that if I have failed to file any compliance reports that have been required of me, I am not eligible and will not be eligible to have my bid considered or to enter into the proposed contract unless and until I make an arrangement regarding such reports that is satisfactory to either the RHS, RBS or RUS, or to the office where the reports are required to be filed. I also certify that I do not maintain or provide for my employees any segregated facilities at any of my establishments, and that I do not permit my employees to perform their services at any location, under my control, where segregated facilities are maintained. I certify further that I will not maintain or provide for my employees any segregated facilities at any of my establishments, and that I will not permit my employees to perform their services at any location, under my control, where segregated facilities are maintained. I agree that a breach of this certification is a violation of the Equal Opportunity clause in my contract. As used in this certification, the term "segregated facilities" means any waiting rooms, work areas, restrooms and wash rooms, restaurants and other eating areas time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees which are segregated by explicit directive or are in fact segregated on the basis of race, creed, color, or national origin, because of habit, local custom, or otherwise. I further agree that (except where I have obtained identical certifications for proposed subcontractors for specific time periods) I will obtain identical certifications from proposed subcontractors prior to the award of subcontracts exceeding $10,000 which are not exempt from the provisions of the Equal Opportunity clause; that I will retain such certifications in my files; and that I will forward the following notice to such proposed subcontractors (except where the proposed subcontractors have submitted identical certifications for specific time periods): According to die Papenvark Reduction Act of 2995, an agency may not conduct or sponsor, o na a persun s nv, rry"nr" ,� , � Fn - .- .,..__..... -, .._--- unless-Il displays the validrk Reduction l aninnhen[ The vavalid OMB control mmnher for this information collection is 0575-0018. The time required to ca)nplete-this information collection is estimated to average 10 mimnes per response, including the timejr revieiviiig insfrriclions, searchingaris7ing data sources, gathering and matnta/ming the data needed, and completing and reviewing the collection of h formation. Position 6 RD 400-6. (Rev. 12-09) NOTICE TO PROSPECTIVE SUBCONTRACTORS OF REQUIREMENTS FOR CERTIFICATIONS OF NON -SEGREGATED FACILITIES A certification of Nonsegregated Facilities, as required by the May 9, 1967, order (32F.R. 7439, may 19, 1967) on Elimination of Segregated Facilities, by the Secretary of Labor, must be submitted prior to the award of a subcontract exceeding $ 10,000 which is not exempt from the provisions of the Equal Opportunity clause. The certification may be submitted either for each subcontract or for all subcontracts during a period (i.e., quarterly, semiannually, or annually). NOTE: The penalty for making false statements in offers is prescribed in 18 U.S.C. 1001. U.S. DEPARTMENT OF AGRICULTURE Certification Reggarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions This certification is required by the regulations implementing Executive Order 12549, Debarment and Suspension, 7 CFR Part 3017, Section 3017.510, Participants' responsibilities. The regulations were published as Part IV of the January 30, 1989, Fed eral Register (pages 4722-4733). Copies. of the regulations may be obtained by contacting the Department of Agriculture agency with which this transaction originated. (BEFORE COMPLETING CERTIFICATION, READ INSTRUCTIONS ON REVERSE) (1) The prospective lower tier participant certifies, by submission of this proposal, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department or agency. (2) Where the prospective lower tier participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal. Tviie We al PR/Award Number or Project Name Organization Name BR,Ag He,&-e-Abo&F VP Name(s) and Title(s) of Authorized Representative(s) Form AD -1048 (1192) Instructions for Certification 1. By signing and submitting this form, the prospective lower tier participant is providing the certification set out on the reverse side in accordance with these instructions. 2. The certification in this clause is a material representation of fact upon which reliance was placed when this transaction was entered into. If it is later determined that the prospective lower tier participant knowingly rendered an erroneous certification, in addition to other remedies available to the Federal Government, the department or agency with which this transaction originated may pursue available remedies, including suspension and/or debarment. 3. The prospective lower tier participant shall provide immediate written notice to the person to which this proposal is submitted if at any time the prospective lower tier participant learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances. i 4. The terms "covered transaction,»" debarred,"n suspended,""ineligible,"cc lower tier covered transaction, "participant," "person," "primary covered transaction," "principal," "proposal," and "voluntarily excluded," as used in this clause, have the meanings set out in the Definitions and Coverage sections of rules implementing Executive Order 12549. You may contact the person to which this proposal is submitted for assistance in obtaining a copy of those regulations. 5. The prospective lower tier participant agrees by submitting this form that, should the proposed covered transaction be entered into, it shall not knowingly enter into any lower tier covered transaction with a person who is debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction, unless authorized by the department or agency with which this transaction originated. 6. The prospective lower tier participant further agrees by submitting this form that it will include this clause titled "Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions," without modification, in all lower tier covered transactions and in all solicitations for lower tier covered transactions. q* A participant in a covered transaction may rely upon a certification of a prospective participant in a lower tier covered transaction that it is not debarred, suspended, ineligible, or voluntarily excluded from the covered transaction, unless it knows that the certification is erroneous. A participant may decide the method and frequency by which it determines the eligibility of its principals. Each participant may, but is not required to, check the Nonprocurement List. 8. Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render in good faith the certification required by this clause. The knowledge and information of a participant is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings. 9. Except for transactions authorized under paragraph 5 of these instructions, if a participant in a covered transaction knowingly enters into a lower tier covered transaction with a person who is suspended, debarred, ineligible, or voluntarily excluded from participation in this transaction, in addition to other remedies available to the Federal Government, the department or agency with which this transaction originated may pursue available remedies, including suspension and/or debarment. - _ _ — - --- Form AD -1048 (1/92 .U. 8,GPO: 1996.757.7761201 07 RD Instruction 1940-Q Exhibit A-1 CERTIFICATION FOR CONTRACTS, GRANTS AND LOANS The undersigned certifies, to the best of his or her knowledge and belief, that: 1. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant or Federal loan, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant or loan. 2. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant or loan, the undersigned shall complete and submit Standard Form - LLL, "Disclosure of Lobbying Activities," in accordance with its instructions. 3. The undersigned shall require that the language of this certification be included in the award documents for all subawards at all tiers (including contracts, subcontracts, and subgrants under grants and loans) and that all subrecipients shall certify and disclose accordingly. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by section 1352, title 31, U.S. Code. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. (title) M. (date) (08-21-91) PN 171 RD Instruction 1942-A Guide 18 Page 7 14. Certificate of Owner's Attorney. I, the undersigned, NL�i� 1il�„'d7. (f I) the duly authorized and acting legal representative of ( yC6 C V Lc G-,) i C 1 �� F4 C, U do hereby certify as follows I have examined the attached contract(s) and performance and payment bond(s) and the manner of execution thereof, and I am of the opinion that each of the aforesaid agreements are adequate and have has been duly executed by the proper parties thereto acting through their duly authorized representatives; that said representatives have full power and authority to execute said agreements on behalf of the respective parties named thereon; and that the foregoing agreements constitute valid and legally binding obligations upon the parties executing the same in accordance with terms, conditions, and provisions thereof. Date: NOTE: Delete phrase "performance and payment bonds" when not applicable. (2-19-86)- -PN-998- --- --- Blair Public Library and Technology Center Blair, Nebraska 862-001-14 SECTION 00 42 00 - BID FORM BID PROPOSAL FOR CONTRACT FOR Blair Public Library Foundation Blair Public Library and Technology Center Blair, Nebraska Date: 11/4/2015 Submitted To: Blair Public Library Foundation Submitted By: The Weitz Company Addenda Received: 2 The undersigned, having examined the plans, project manuals and related documents, and the site of the proposed work, and being familiar with all of the bonditions surrounding the construction of the proposed project, including the availability of labor, hereby proposes to furnish all labor, materials and supplies to do the work in accordance with the Contract Documents and terms and condition described below: Recognizing that time will be of the essence, the undersigned proposes, upon execution of the Agreement Between Owner and Contractor or upon receipt of notice to proceed from the Owner (whichever comes first), to immediately start the Work of the Contract. The Agreement Between Owner and Contractor will be executed as soon as possible after the opening and award of bids. The undersigned proposes to bring the work to a state of Substantial Completion on or before July 1, 2017. Markup percentage for all changes in the work shall not exceed 10%. This shall include all overhead and profit associated with each change. See Section 01 26 00, "Contract Modification Procedures", for administrative and procedural requirements for handling and processing contract modification. See Section 01 21 00, "Allowances" for exceptions to this requirement. Execution of Agreement: The undersigned will, within fourteen (14) days of receipt of notice of acceptance of this proposal, enter into agreement with the Owner on the Owner's agreement form and will deliver the required Performance Bond and Labor and Materials Payment Bond. TOTAL PRICE: The undersigned proposes to perform the Work shown/described in the bidding documents for the sum of: 10/15 BID FORM 004200- 1 �The Clark Enersen , Partners Blair Public Library and Technology Center Blair, Nebraska 862-001-14 10/15 ALTERNATES: 1. Alternate No. A-1 - Alternative Start and Completion Dates with Cost Change. See Section 0123 00 Alternates. '�'' (Alternate No. A-11): Anticipated Start Date t Al C t Anticipated Completion Date \ , " Change in Total PricejCfEof rs ($� 2. Alternate No. A-2 - ACM Cornice Detail. See Section 0123 0 Alternates. (Alternate No. A-2): vtx 3. Alternate No. A-3 - Appliances. See Section 0123 00 Alternates. (Alternate No. A-3): 4°t ,tom`` - �`P� 4. Alternate No. A-4 - Trellis. See Section 0123 00 Alternates. (Alternate No. A-4): 1$.-3 jk 0 o . 6. Alternate No. LA -Trash Enclosure. See Section 0123 00 Alternates. C� (Alternate No. L-1): 6. Alternate No. E-1- Auxiliary Systems. See Section 0123 00 Alternates. a (Alternate No. E-1): $ �,�� ) UNIT PRICES: vrL 1. Unit Price No. 1 - 6" thick concrete pavement. See Sec_ti9p�0�1 22 0fUnit Prices. (Unit Price No. 1): ` s-� , $7SY) 2. Unit Price No. 2t-"4' ck reinforced sidewalk. See Section, 1/J00 Unit Prices. -&(Unit Price No. 2): , $ o �ISF) 3. Unit Price No. 3 - Bike Loop installed. See Section 0122 00 Unit Prices. (Unit Price No. 3): � O , $ 0.10?Each) 004200- 2 BIO FORM r The Enersen 0°, Partners Blair Public I.ibrpry and Technology Center Blair, Nebraska 862-001-14 Respectfully Submitted, (Signature) The Weitz Company (Company) 8715 s. 121 st Street La Vista, NE 68128 (Business Address) 402-592-7000 (Telephone Number) END OF SECTION 00 42 00 A The Clark Ener5en partners (Seel, if by a Corporation) 10/15 004200- 3 THE AMERICAN -INSTITUTE OF ARCHITECTS AIA Document A310 Bid Bond - KNOW ALL MEN BY THESE PRESENTS, THAT WE The Weitz Company, LLC 8715 S. 121st Street, La Vista, NE 68128 as Principal, hereinafter called the Principal and Fidelity and Deposit Company of Maryland 1400 American Lane, Tower 1,18th floor, Schaumburg, IL 60196 a corporation duly organized under the laws of the State of Maryland � • as Surety., hereinafter called the Surety, are held and firmly bound unto Blair Public Library Foundation 218 S. 16th. Street, Blair, NE 68008 as Obligee, hereinafter called the Obligee, in the sum of Five (5%) of the total amount of bid Dollars ($ for the payment of which•sum well and truly to be made, the -said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these prbsebts, WIAEREAS, the Principal has submitted a bid for Blair Public Library and Technology Center NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter Into a Contract with the Obligee In accordance with the terms of such bid, and give such bond or hbnds as may be specified in the bidding or Contract Documents with good and sufficient. surety for the faithful performance of such Contract and for the prompt payment of labor and materials furnished in the prosecution thereof, or in the event of the failure of the Principal to enter such Contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may In good faith contract with another party to perform the Work covered by said bid, then this obligation shall be null and void, otherwise to remain In full force and effect. October 2015 th 30 Signed and sealed this day of ' A� • ' /� �. - Fidelity and Deposit Company of Maryland . DOCUMENT A310 O BID BOND o AIA P FEBRTIATtY 1970 ED. • THE AMMUC:AN INSTITUTE OT ARCHITECTS,1735 N.i'. AVE.,IV.W., WASHINGTON,-D.C.20 0 -_— CALIFORNIA• •WLEDGMENT CIVIL CODE § 1189 `t!a . �•v • .ve.: :!c�•.w sit_wea> .w at�u�..w _w _a�._w . c�.r Tp.. _.�.>..w .c�< �t.w . v..w<� •.v..w..a�..w .wa. t.a..w .w rc� wc.:m. A notary public or other officer completing this certificate verifies only the.identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document State of California County of Contra Costa On 0-to-b'.f 3o ii O/,%e ore me, _ Date personally appeared Lisa M. Lucas Tanya Chinchilla, Notary Public Here Insert Name and Title of the Officer Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(b) whose name( is/ subscribed to the within instrument and acknowledged to me that Doe/she/Iiw executed the same in I)Wher/AW authorized capacityOM), and that byXii/herAIINiKsignature(g) on the instrument the person(*, or the entity upon behalf of which the person(R) acted, executed the Instrument. TANYA CHINCHILLA Commission # 2127934 a Notary Public - California z Contra Costa County My Comm. Expires Se 26 2019 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph Is true and correct. WITNESS my hand and official seal. Signature �aturrof Notary Public Place Notary Seal Above • OPTIONAL Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named' Above: Capacity(ies) Claimed by Signer(s) Signer's Name: ❑ Corporate Officer •— Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator M n}hPr. Signer Is Representing: Signer's Name: ❑ Corporate Officer •— Title(s): ❑ Partner — ❑ Limited ❑ General 0 -individual ❑ Attorney in Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other:. Signer Is Representing: 02014 National Notary Association : wwNr.NationalNotary.org - 1 -800 -US NOTARY (1-800-876-fi827) Item -#5907 i L2 y'1 ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY •COMPANY FIDELITY AND DEPOSIT COMP.A W OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, -a corporatior7 of the State of Maryland, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the 'State of Maryland (herein collectively called the "Companies".), by JAMES M. CARROLL, Vice President, in pursuance of authority granted by Article V, Section 8, of the By -Laws of said Companies, which are set forth on the reverse -side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, atxd appoint D. Richard-STINSON, LisaM. LUCAS, William EH MLIPS JR., A.WI:BROWN and Tanya CHINCHILLA„ -all of San Ramon, California, EACH its true and lawful agent and Attomey4n-Fact, to make, execute, seal •and deliver, for, and on its behalf as surety, and as its act and deed: any and -all bonds and undertaldugs, and the execution: of suchbonds or undertakings in pursuance of these presents, shall be as binding upon said Companies, as fully and amity, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New York., the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT'COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. Thu said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of the By -Laws of said Companies, and is now -in force. IN WITNESS WHEREOF, the said Vice President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 17th day of September, A.D. 2012. ATTEST.- ZURICH TTEST; BY Seerefaly - E'�dc ll. Barites ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND . OLPOfr Jd0Gp��....�R.4 �HUIbpU". Vice President ,Tames M. Carroll State of Maryland County ofBaltimore On this 17th day of September, A.D. 2012, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, JAMES M. CARROLL, Vice President, and ERIC D. BARNES, Secretary, of the Companies, to me personallyknown to be the individuals and officers described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly swom, deposeth and saith, that helshe is the said officer of the Company aforesaid, and that the seals affixed to the preceding instnunent are the Corporate Seals of said Companies, and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY 14HEREOF, I have hereunto set my hand and affixed my Official Seal the day and yearfirst above written. • `,�ry1`.C+�.ci'''c+2' Q. �..unwv �' J PIJ a4`�J1�fi --- — - — Constance A. Dunn, -Notary Public--- - My Commission Expires: July 14, 2015 •POA -F 016-00840 Bond No. 9209452 Document A312 TM -2010 Conforms with The American Institute of Architects AIA Document 312 Payment Bond CONTRACTOR: (Nance, legal status and address) The Weitz Company, LLC 420 Watson Powell Jr. Way Des Moines, IA 50309 OWNER: (.frame, legal status and address) Blair Public Library Foundation 218 S. 16th Street Blair, NE 68008 CONSTRUCTION CONTRACT Date: t\ lie, 1 15' Amount: $4,222,500.00 SURETY: (Name, legal status and prinelpal place of business) Fidelity and Deposit Company of Maryland 1400 American Lane, Tower I, 18th Floor Schaumburg, IL 60196-1056 Mailing Address for Notices 600 Red Brook Blvd., 4th Floor Owing Mills, MD 2117 This document has important legal consequences. Consultation with an attorney is encouraged with respect to Its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. Four Million Two Hundred Twenty Two Thousand Five Hundred Dollars and 00/100 Description: (Nance and location) Blair Public Library and Technology Center Deerfield Addition, Los 86, Deerfield Drive and US Hwy 75, 1001 Civic Center Drive, Blair NE BOND Date: January 7, 2016 (Not earlier than Construction Contract Date) Amount: $4,222,500.00 Four Million Two Hundred Twenty Two Thousand Five Hundred Dollars and 00/100 Modifications to this Bond: ® None F1 See Section 18 CONTRACTOR AS PRINCIPAL. Company: (Corporate Seal) The Weitz Company, LLC Signature.,110a.e g Name and Title: SURETY Company: (Corporate Seal) Fidelity and Deposit Company of Maryland Signature: V ate® , Namo C.K. Nakamura and Title: Attorney -in -Fact (Any additional signatures appear on the last page of this Payment pond..) (FOR INFORbIRTIO.V ONLY—Al'ame, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: Alliant Insurance Services, Inc. (Architect, Engineer orotherparlyr) 333 S: Hope Street,, -Suite 3750 — Clark-Enersen-Grou _ _-_ p -- Los Angeles, CA 90071 1010 Lincoln Mail; Suite 200 - Lincoln, NE 68508 213-443-2467 8-2149/AS 8/10 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is Incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner docs not request a conference, the Surety may, within five (5) business days afterrecelpt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price In accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner, or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days atter receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform Its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 8•18521AS 8/10 § 7 If the Surety elects to act under Section 5.1, 5.2 or 5,3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for ,1 the responsibilities of the Contractor for correction of defective work and completion of the. Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 -liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 I the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9'Me Surety shall not be liable to the Owner or others for obligations of the Contractor that arc unrclotdd to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, Iegal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law, the minitnum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable, § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. . § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefiom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so fbmished, the intent is that this Bond shall be construed as a statutory bond and not as a common law'bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner In settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. 'Phe agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not boon remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default, Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 if this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor In this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. 6-1852/A$8/10 § 16 Modifications to this bond are as follows: (Space is provided below for additional signakires of addedpardes, other than those appearing on the coverpage.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address Address 5-18521A8 8110 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT Civil Code § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy or validity of that document. State of California ) ss County of Los Angeles ) On JAN 07 2016 , before me, Patricia Arana, Notary Public, personally appeared C.K. Nakamura , who proved to me on the basis of satisfactory evidence to be the person{) whose nameN is/aite subscribed to the within instrument and acknowledged to me that 4e/sheA4ey executed the same in 4i.&/her44e* authorized capacity4-4, and that by 4js/herA4+e# signatureks- on the instrument the person¢s-), or the entity upon behalf of which the persons acted, executed the instrumerit. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. PATRICIA ARANA Commission # 2043063 z a --� Notary Public - California z Z Los Angeles County a Mx Comm. Expires Se 27, 2017 Signature: (Seal) t ' a Arana, Notary Public Bond No. 9209452 Document A312TM -2010 Conforms with The American Institute of Architects AIA Document 312 Performance Bond CONTRACTOR: (Nance, legal status and address) The Weitz Company, LLC 420 Watson Powell Jr. Way Des Moines, IA 50309 OWNER: (Name, legal staUrs and address) Blair Public Library Foundation 218 S. 16th Street Blair, NE 68008 CONSTRUCTION CONTRACT Date: 1,1 /to /?_0t5 Amount:$ 4,222,500.00 SURETY: (Name, legal status and princlpal place of business) Fidelity and Deposit Company of Maryland 1400 American Lane, Tower I, 18th Floor Schaumburg, IL 60196-1056 Mailing Address for Notices 600 Red Brook Blvd., 4th Floor Owing Mills, MD 2117 This document has Important legal consequences. Consultation with an attorney is encouraged with respect to Its completion or moditicallon. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. Four Million Two Hundred Twenty Two Thousand Five Hundred Dollars and 00/100 Description: (Nante and location) Blair Public Library and Technology Center Deerfield Addition, Los 86, Deerfield Drive and US Hwy 75, 1001 Civic Center Drive, Blair NE BOND Dato: January 7, 2016 (Not earlier than Conspvretlon Contract Date) Amount: $ 4,222,500.00 Modifications to this Bond: ® None CONTRACTOR AS PRINCIPAL Four Million Two Hundred Twenty Two Thousand Five Hundred Dollars and 00/100 El Soo section 16 SURETY Company: (Coi porate Seal) Fidelity and Deposit Company of Maryland Signature: Name C.K. Nakamura and Title: Attorney -in -Fact (Any additional signatures appear on the last page of this Performance Bona:) (FOR INFORUANON ONLY --Name, address and telephone) AGENT or BROKER: OWNE=R'S REPRESENTATIVE: Alliant Insurance Services, Inc. (Wehitect, Engineer orotherparty:) - - S. Hope Street; -Suite 3750 ---- -Clark Enersen Group- roupLos LosAngeles, CA 90071 1010 Lincoln Mali, Suite 200 Lincoln, NE 68508 213-443-2467 S-1852IAS 8/10 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and dcfcnds, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 if there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner tinder this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owncr°s property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit, § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 6.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13), § 5.2 Claimants, who arc employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13), § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section S.I.I. § 7 When a Claimanthas satisfied the conditions of Sections 5.1 or 5,2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) clays ufter receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and § 7.2 pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7,2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attumey's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant, § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. , 8-2149/AS 8/10 § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant underthis Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction In the state in which the project that is the subject of the Construction Contractis located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last tabor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) frst occurs. if the provisions of this Paragraph are void orprohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears, Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been finmished to comply with a statutory or other legal requirement In the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefiom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 16 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A vallten statementby the Claimant including at a minimum; .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement orpurchase order pursuant'to which labor, materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .6 the date on which the Claimant last performed labor or last furnished materials or equipmentfor use in the performance of the Construction Contract; .6 the total amount tamed by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount ofprevious payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has . rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located, The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required forperformance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in tho jurisdiction whore the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents, 8-2149/AS 8110 § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 96.6 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 1S Modifications to this bond are us follows: (Space is provided below for additional signatures of addedpartles, other than those appearing on Bre cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (CorporateSea1) Signature: Signature: Name and Title: Name and Title: Address Address S-2149/AS 8110 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT Civil Code § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy or validity of that document. State of California ) ) ss County of Los Angeles ) ' 7 2016 On `' A I , before me, Patricia Arana, Notary Public, personally appeared C.K. Nakamura , who proved to me on the basis of satisfactory evidence to be the person464 whose name{ is/afe subscribed to the within instrument and acknowledged to me that #e�sheA-hey executed the same in *41her4heif authorized capacity4&s4, and that by 44/her & signature{4 on the instrument the person{&}, or the entity upon behalf of which the person{4 acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. PATRICIA ARANA Commission # 2043063 z i`m a Notary Public - California a Los Angeles County My Comm. Expires Sep 27, 2017 (Seal) Signature:' Pa is Arana, Notary Public ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS: That the ZURICH AMERICAN INSURANCE COMPANY, a corporation of the State of New York, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, a corporation of the State of Maryland, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND a corporation of the State of Maryland (herein collectively called the "Companies"), by GERALD F. HALEY, Vice President, in pursuance of authority granted by Article V, Section 8, of the By -Laws of said Companies, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, do hereby nominate, constitute, and appoint C. K. NAKAMURA, Lisa L. THORNTON, E. S. ALBRECHT JR., Maria PENA and Noemi QUIROZ, all of Los Angeles, California, EACH its true and lawful agent and Attomey-in-Fact, to make, execute, seal and deliver, for, and on its behalf as surety, and as its act and deed: any and all bonds and undertakings, and the execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said Companies, as fully and amply, to all intents and purposes, as if they had been duly executed and acknowledged by the regularly elected officers of the ZURICH AMERICAN INSURANCE COMPANY at its office in New York, New York., the regularly elected officers of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at its office in Owings Mills, Maryland., and the regularly elected officers of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at its office in Owings Mills, Maryland., in their own proper persons. The said Vice President does hereby certify that the extract set forth on the reverse side hereof is a true copy of Article V, Section 8, of the By -Laws of said Companies, and is now in force, IN WITNESS WHEREOF, the said Vice -President has hereunto subscribed his/her names and affixed the Corporate Seals of the said ZURICH AMERICAN INSURANCE COMPANY, COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 17th day of December, A.D. 2014. ATTEST: ZURICH AMERICAN INSURANCE COMPANY COLONIAL AMERICAN CASUALTY AND SURETY COMPANY FIDELITY AND DEPOSIT COMPANY OF MARYLAND SEAL i� 1908 ;'a3 X"d �- W-� Secretary Vice President Michael McKibben Gerald F. Haley State of Maryland County of Baltimore On this 17th day of December, A.D. 2014, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, GERALD F. HALEY, Vice President, and MICHAEL MCKIBBEN, Secretary, of the Companies, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and acknowledged the execution of same, and being by me duly sworn, deposeth and saith, that helshe is the said officer of the Company aforesaid, and that the seals affixed to the preceding instrument are the Corporate Seals of said Companies, and that the said Corporate Seals and the signature as such officer were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporations. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. ,Ii Maria D. Adamski, Notary Public - My Commission Expires: July8-12019---- - POA -F 012-0115D EXTRACT FROM BY-LAWS OF THE COMPANIES "Article V, Section 8, Attomevs-in-Fact. The Chief Executive Officer, the President, or any Executive Vice President or Vice President may, by written instrument under the attested corporate seal, appoint attorneys -in -fact with authority to execute bonds, policies, recognizances, stipulations, undertakings, or other like instruments on behalf of the Company, and may authorize any officer or any such attorney-in-fact to affix the corporate seal thereto; and may with or without cause modify of revoke any such appointment or authority at any time." CERTIFICATE I, the undersigned, Vice President of the ZURICH AMERICAN INSURANCE COMPANY, the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY, and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, do hereby certify that the foregoing Power of Attorney is still in full force and effect on the date of this certificate, and I do further certify that Article V, Section 8, of the By -Laws of the Companies is still in force. This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the ZURICH AMERICAN INSURANCE COMPANY at a meeting duly called and held on the 15th day of December 1998. RESOLVED: "That the signature of the President or a Vice President and the attesting signature of a Secretary or an Assistant Secretary and the Seal of the Company maybe affixed by facsimile on any Power of Attorney ...Any such Power or any certificate thereof bearing such facsimile signature and seal shall be valid and binding on the Company." This Power of Attorney and Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the COLONIAL AMERICAN CASUALTY AND SURETY COMPANY at a meeting duly called and held on the 5th day of May, 1994, and the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 10th day of May, 1990. RESOLVED: "That the facsimile or mechanically reproduced seal of the company and facsimile or mechanically reproduced signature of any Vice -President, Secretary, or Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be valid and binding upon the Company with the same force and effect as though manually affixed. IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seals of the said Companies, this _day of , 20_ JAN 07 2016 Fav ocros, ��t-INs�� W=� � K tri i `4 _•_ jc REAL � s.1 1688 r'a� Michael Bond, Vice President ACOR 1 0 CERTIFICATE OF LIABILITY INSURANCE 6/In016 DATE (MM/DD/YYYY) 1/8/2016 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Lockton Companies 444 W. 47th Street, Suite 900 Kansas City MO 64112-1906 (816)960-9000 ACT NAME: aiOPHONE FAX Ext): No E-MAIL ADDRESS: INSURER(S) AFFORDING COVERAGE NAIC # INSURER A: ACEAmellcan Insurance Compoy Company22667 6/1/2016 INSURED THE WEITZ COMPANY, LLC 1360869 WEITZ NEBRASKA INSURER B: INSURER C: INSURER D : 5901 THORNTON AVE, DES MOINES IA 50321 INSURER E: INSURER F: PRODUCTS- COMP/OPAGG $ 4,000,000 COVERAGES CERTIFICATE NUMBER: 13838174 REVISION NUMBER: XKXXXXX THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. TR TYPE OF INSURANCE ADDL D SUBR POLICY NUMBER POLICY EFF MM/DDNYYY POLICY EXP MMIDD/YYYY LIMITS A X COMMERCIAL GENERAL LIABILITY � OCCUR Y N HDOG24556438 6/1/2015 6/1/2016 EACH OCCURRENCE $ 2,000,000 DAMACLAIMS-MADE PREMISES Ea occurE TO rence $ 100,000 MED EXP (Any one person) $ 10,000 PERSONAL & ADV INJURY $ 2,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: POLICYFX] JECT PRO-- LOC OTHER: GENERAL AGGREGATE $ 4,000,000 PRODUCTS- COMP/OPAGG $ 4,000,000 A AUTOMOBILE LIABILITY X ANY AUTO ALL OWNED SCHEDULED AUTOS AUTOS NON -OWNED X HIRED AUTOS Ix IAUTOS Y 11 CALHO8878328 6/1/2015 6/1/2016 Ea BINEDaccidenISINGLE LIMIT $ 2 '000,000 BODILY INJURY (Per person) $ XXXXXXX BODILY INJURY (Per accident) $ XXXXXXX DAMAGE PROPERTY D$XXXXXXX Per accident $XXXXXXX UMBRELLA LIAB EXCESS LIAB OCCUR CLAIMS -MADE NOTAPPLICABLE EACH OCCURRENCE $ XXXXXXX AGGREGATE $ XXXXXXX DED I I RETENTION$ $ XXXXXXX • A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE Y / N OFFICER/MEMBER EXCLUDED? FNI (Mandatory In NH) It yes, describe under DESCRIPTION OF OPERATIONS below N / A N SCFC47853382 (WI) WLRC47853382 (AOS) 6/1/2015 6/1/2015 6/1/2016 6/1/2016 X STATUTE ERH E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 E.L, DISEASE - POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS I VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached If more space is required) PROJECT: BLAIR PUBLIC LIBARY AND TECHNOLOGY CENTER. BLAIR PUBLIC LIBARY FOUNDATION IS AN ADDITIONAL INSURED ON GENERAL AND AUTO LIABILITY, IF REQUIRED BY WRITTEN CONTRACT AND SUBJECT TO THE TERMS AND CONDITIONS OF THE POLICY. THIRTY (30) DAYS NOTICE OF CANCELLATION BY THE INSURER WILL BE PROVIDED TO THE CERTIFICATE HOLDER, TEN (10) DAYS NOTICE IN THE EVENT OF NONPAYMENT OF PREMIUM). 13838174 BLAIR PUBLIC LIBARY FOUNDATION 218 S 16TH STREET BLAIR NE 68008-- SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE _WITH THE_P_OLICY PROVISIONS. AUTHORIZED ©19BBL�014 ACORD CORPORATION. All riahts reserved. ACORD 25 (2014/01) The ACORD name and logo are registered marks of ACORD EVIDENCE OF COMMERCIAL PROPERTY INSURANCE DATE (YYYY) - 1/8/20168/2016aJ2ol6 THIS EVIDENCE OF COMMERCIAL PROPERTY INSURANCE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE ADDITIONAL INTEREST NAMED BELOW. THIS EVIDENCE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS EVIDENCE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE ADDITIONAL INTEREST. PRODUCER NAME,PHONE CONTACT PERSON AND ADDRESS AIC No Ext : (816) 960-9000 COMPANY NAME AND ADDRESS NAIC NO: 20702 Lockton Companies ACE Fire Underwriters Insurance Company 444 W. 47th Street, Suite 900 Actual Loss Sustained; # of months: Kansas City MO 64112-1906 IF MULTIPLE COMPANIES, COMPLETE SEPARATE FORM FOR EACH FAIC No : ADDAIL RESS: TERRORISM COVERAGE CODE: SUB CODE: POLICYTYPE Property CUSTOMER ID IS THERE A TERRORISM -SPECIFIC EXCLUSION? NAMED INSURED AND ADDRESS THE WEITZ COMPANY LLC LOAN NUMBER POLICY NUMBER 1114868 WEITZ NEBRASKA IS DOMESTIC TERRORISM EXCLUDED? I08856412001 5901 THORNTON AVE. EFFECTIVE DATE EXPIRATION DATE CONTINUED UNTIL DES MOINES IA 50321 6/1/2015 6/IJ2D17 TERMINATED IF CHECKED ADDITIONAL NAMED INSURED(S) THIS REPLACES PRIOR EVIDENCE DATED: PROPERTY INFORMATION (Use KhMAHKti on page z, II mores ace Is re ulrea) LJ 6UILUII4U cin LJ 0U0II4000 rGn.7v14A" rnvrcn 1 . LOCATION ( DESCRIPTION START DATE: 4/1/16 EST. COMPLETION DATE: 2/30/17 LOCATION: 1001 CIVICDRIVE CONTRACT AMOUNT: $4,222,500 BLAIR NE 68008 THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS EVIDENCE OF PROPERTY INSURANCE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ..... �.. _ .............._.. ...... .... .... - COMMERCIAL PROPERTY COVERAGE AMOUNT OF INSURANCE: $ -� •- - ------ ----COMMERCIAL 4,222,5000 DED: 10,000 AOP NAME AND ADDRESS YES NO NIA - - 218 S -16TH STREET- ❑ BUSINESS INCOME ❑ RENTAL VALUE X AUTHORIZED R pESENTATIVE If YES, LIMIT: Actual Loss Sustained; # of months: BLANKET COVERAGE X If YES, indicate value(s) reported on property Identified above: $ TERRORISM COVERAGE X Attach Disclosure Notice / DEC IS THERE A TERRORISM -SPECIFIC EXCLUSION? X IS DOMESTIC TERRORISM EXCLUDED? X LIMITED FUNGUS COVERAGE X If YES, LIMIT: DED: FUNGUS EXCLUSION (If "YES", specify organization's farm used) X REPLACEMENT COST X AGREED VALUE X COINSURANCE X DYES, EQUIPMENT BREAKDOWN (If Applicable) X If YES, LIMIT: DED: ORDINANCE OR LAW - Coverage for loss to undamaged portion of bldg X If YES, LIMIT: 1,000,000 DED: Demolition Costs X If YES, LIMIT: 1,000,000 DED: - Incr. Cost of Construction X If YES, LIMIT: 1,000,000 DED: EARTH MOVEMENT (if Applicable) X If YES, LIMIT: 4,222,5000 DED: 25,000 FLOOD (If Applicable) . X If YES, LIMIT: 4,222,5000 DED: 10,000 WIND / HAIL INCL ❑ YES (] No Subject to Different Provisions: X if YES, LIMIT: DED: NAMED STORM INCL ❑ YES p NO Subject to Different Provisions: X If YES, LIMIT: DED: PERMISSION TO WAIVE SUBROGATION IN FAVOR OF MORTGAGE HOLDER PRIOR TO LOSS X CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. VP ^v MORTGAGEE LENDERS LOSS PAYABLE H CONTRACT OF SALE LENDER SERVICING AGENT NAME AND ADDRESS NAME AND ADDRESS 511137 BLAIR PUBLIC LIBRARY FOUNDATION - - 218 S -16TH STREET- - - - - - - -- - -- BLAIR NE 68008 AUTHORIZED R pESENTATIVE /J I ne AL;UKu name ana logo are registerea marcs 01 rtt,vnL+' v AUua-4u 1 1 IWI'4. -11 1111110 1 GJG1 ACORD 28 (2014/01) For questions regarding this certificate, contact the number listed in Ihe'Producer'section above.